Terms and Conditions

Acceptance of Terms

By accessing or using the website at lakeclarkeshoressunroomsandpatios.com or by engaging Lake Clarke Shores Lanai Sunrooms & Patios for services, you agree to be bound by these Terms and Conditions. If you do not agree with any part of these terms, please do not use this website or engage our services.

These terms apply to all visitors to our website and to all clients who enter into a service agreement with Lake Clarke Shores Lanai Sunrooms & Patios.

Description of Services

Lake Clarke Shores Lanai Sunrooms & Patios provides sunroom construction, installation, remodeling, and related services in Lake Clarke Shores, FL and surrounding communities. The specific scope of services for each project is defined in a written proposal or contract provided to the client prior to the start of work.

Nothing on our website constitutes a binding offer or guarantee of services, pricing, or availability. Services are subject to our capacity, geographic coverage, and the requirements of each individual project.

Estimates and Pricing

Initial estimates provided verbally or during a site visit are non-binding approximations based on the information available at that time. A formal written proposal will be provided before any work begins. The written proposal, once signed by both parties, constitutes the agreed price and scope.

Prices are subject to change if the scope of work changes, if unforeseen site conditions are discovered during construction, or if material costs change significantly between the estimate and the start of work. Any changes to the agreed price will be communicated in writing and require your approval before work proceeds.

Free estimates are provided at no cost or obligation and do not create a contractual relationship between you and Lake Clarke Shores Lanai Sunrooms & Patios.

Scheduling and Cancellation

Project scheduling is confirmed in the written contract. Start dates are subject to permitting timelines, material availability, and weather conditions. Lake Clarke Shores Lanai Sunrooms & Patios will communicate any significant scheduling changes as soon as they are known.

If you need to cancel or reschedule a consultation or estimate, please contact us at least 24 hours in advance. Cancellation of a signed contract is subject to the cancellation terms specified in that contract, which may include forfeiture of a deposit to cover costs already incurred.

Payment Terms

Payment terms are specified in the written project contract. Most projects require a deposit at the time of contract signing, with additional payments tied to project milestones, and a final payment due upon completion. Accepted payment methods are stated in the contract.

Late payments may result in a suspension of work until the outstanding balance is resolved. Lake Clarke Shores Lanai Sunrooms & Patios reserves the right to charge interest on balances unpaid beyond the agreed due date, as permitted under Florida law.

In the event a client fails to pay as agreed, Lake Clarke Shores Lanai Sunrooms & Patios reserves all legal remedies available under Florida law, including the right to place a lien on the property for the value of work performed and materials supplied.

Warranty Disclaimers

Any warranty offered on workmanship or materials will be stated expressly in the written project contract. No verbal representations constitute a warranty.

The information on our website is provided "as is" without warranty of any kind. Lake Clarke Shores Lanai Sunrooms & Patios makes no representations or warranties regarding the accuracy, completeness, or suitability of the content on this website for any particular purpose.

Manufacturer warranties on products and materials are separate from any workmanship warranty provided by Lake Clarke Shores Lanai Sunrooms & Patios and are subject to each manufacturer's terms.

Limitation of Liability

To the fullest extent permitted by Florida law, Lake Clarke Shores Lanai Sunrooms & Patios shall not be liable for any indirect, incidental, consequential, or punitive damages arising from the use of our website, reliance on information presented on our website, or any delay or failure in performing services.

Our total liability for any claim arising out of or related to services provided shall not exceed the amount paid by you for the specific services giving rise to that claim.

Lake Clarke Shores Lanai Sunrooms & Patios is not responsible for delays or failures caused by circumstances beyond our reasonable control, including extreme weather events, supply chain disruptions, permit delays, or labor shortages.

Client Responsibilities

You are responsible for providing accurate information about your property and project when requesting an estimate or entering into a contract. You are responsible for notifying your homeowners association, if applicable, and obtaining any required HOA approvals before construction begins. Lake Clarke Shores Lanai Sunrooms & Patios may assist in preparing HOA submissions but is not responsible for HOA approval decisions or delays.

You are responsible for ensuring that utility lines and underground hazards in the work area are located and marked before excavation or foundation work begins. Lake Clarke Shores Lanai Sunrooms & Patios will coordinate with you on this step but relies on you to confirm access arrangements.

Intellectual Property

All content on this website, including text, photographs, graphics, and logos, is the property of Lake Clarke Shores Lanai Sunrooms & Patios or its licensors. You may not reproduce, distribute, or use any content from this website without our written permission.

Dispute Resolution

If a dispute arises between you and Lake Clarke Shores Lanai Sunrooms & Patios regarding services, payment, or the terms of a contract, both parties agree to first attempt to resolve the dispute through direct communication in good faith. If direct communication does not resolve the issue, the parties agree to participate in non-binding mediation before pursuing any formal legal action.

Nothing in this section prevents either party from seeking emergency injunctive or equitable relief from a court of competent jurisdiction.

Governing Law

These Terms and Conditions and any disputes arising from them are governed by the laws of the State of Florida, without regard to its conflict of law provisions. Any legal proceedings arising from these terms or from services provided by Lake Clarke Shores Lanai Sunrooms & Patios shall be brought in a court of competent jurisdiction in Florida.

Modifications to These Terms

Lake Clarke Shores Lanai Sunrooms & Patios may update these Terms and Conditions at any time. The effective date at the top of this page will be updated when changes are made. Continued use of our website or services after any change means you accept the revised terms. We encourage you to review this page periodically.

Contact Us

If you have questions about these Terms and Conditions, please contact us: